Skip to main content

Interest cannot be awarded to buyer for his/her own delay in taking possession

In M/s. Supertech Ltd. VS Rajni Goyal, The dispute concerned a project named ‘Capetown’ developed by the builder in Noida. A flat was allotted by the builder in this development to one Ms. Rajni Goyal in May, 2012, with the Allotment Letter stating that possession would be handed over in October, 2013. The letter allowed extension upto a maximum period of six months due to unforeseen circumstances.

However, the builder handed over a Pre​-Possession Letter to Ms. Goyal only in October 2015, for completion of formalities, before possession could Learn more be handed over. With the letter, she was called upon to pay Rs. 12,35,656 towards the balance cost of the flat and several other charges. She, however, failed to pay the charges.

Ms. Goyal, then, after over fifteen months, in March, 2017, filed a Consumer Complaint before the National Commission which was allowed. Review petition filed against the said order was dismissed after which the builder approached the Supreme Court.

The Supreme Court noted that the Full Occupancy Certificate was obtained by the builder in April 2016, and that Ms. Goyal could not have had any further grievance after that. It, therefore, stating that the Respondent – Purchaser ought not to be allowed to reap the benefits of her own delay in taking possession, directed the period of compensation to be computed from May, 2014 to April, 2016, despite the fact that she approached the Commission in March, 2017.

Comments

Post a Comment

Most viewed this month

Deposit Of Minimum 20% Fine/Compensation U/s 148 NI Act Mandatory

In OP(Crl.).No.348 OF 2019, T.K.SAJEEVAN vs FRANCIS T.CHACKO, the appeal was filed against the order of the lower court to deposit 25% of the fine before filling of appeal. The appellant argued that the deposit introduced through the Section 148 of the NI Act after amendment was directory in nature as it used the term 'may' while mentioning the issue of deposit. The Kerala High Court however disagreeing held that in view of the object of the Legislature while incorporating Section 148 into N.I. Act, the word 'may' will have to be read as 'shall'. The imposition of payment contemplated under Section 148 N.I. Act cannot be restricted to some prosecutions and evaded in other prosecutions. Since the amount directed to be deposited being compensation, undoubtedly, it is liable to be ordered to be deposited irrespective of the nature of the prosecution. Therefore, the word 'may' can only be taken to have the colour and meaning of 'shall' and there
Post a Comment
Read more

NCLT - Mere admission of receipt of money does not qualify as a financial debt

Cause Title : Meghna Devang Juthani Vs Ambe Securities Private Limited, National Company Law Tribunal, Mumbai, CP (IB) No. 974/MB-VI/2020 Date of Judgment/Order : 18.12.2023 Corum : Hon’ble Shri K. R. Saji Kumar, Member (Judicial) Hon’ble Shri Sanjiv Dutt, Member (Technical) Citied:  Carnoustie Management India Pvt. Ltd. Vs. CBS International Projects Private Limited, NCLT Swiss Ribbons Pvt. Ltd. & Anr vs. Union of India & Ors. (2019) Sanjay Kewalramani vs Sunil Parmanand Kewalramani & Ors. (2018) Pawan Kumar vs. Utsav Securities Pvt Ltd 2021 Background Application was filed under section 7 of the Insolvency and Bankruptcy Code, 2016 alleging loan of Rs, 1.70 cr is due. The Applicate identified herself as the widow and heir of the lender but could not produce any documents proving financial contract between her Late husband and the CD but claimed that the CD has accepted that money was received from her husband. The applicant subsequently filed rejoinder claiming the debt t
Post a Comment
Read more

Vanishing promoters and languishing shareholders

Over Rs 60,000 crore of shareholders’ wealth is stuck in 1,450 companies suspended by the stock exchanges. More importantly, near 100 per cent pledging of promoter holding appears to be common in many of these companies. This, almost rules out any chance of the companies bouncing back. The suspension is for non-compliance of the listing norms. Vanishing Companies - Definition As per the definition stipulated by SEBI, any listed company, which raised moneythrough initial public offer and, thereafter, stopped operations, did not file returnseither with the RoC or SEBI and did not exist on the registered premises wastermed as vanishing.There are provisions under Companies Act under which companies are termedvanishing companies on satisfying certain conditions. it is provided a companywould be deemed to be a vanishing company, if it satisfies all the conditions given below : a) Failed to file returns with Registrar of Companies (ROC) for a period of two years; b) Failed to fil
3 comments
Read more