Skip to main content

Whether time is of the essence in a contract is not dependent only a clause in the contract

In WELSPUN SPECIALTY SOLUTIONS LIMITED (FORMERLY KNOWN AS REMI METALS GUJARAT LTD.) vs OIL AND NATURAL GAS CORPORATION LTD., appeal was filed against the  judgment of High Court of Uttarakhand at Nainital setting aside an arbitration award.

The entire dispute and claim before the Arbitrator revolved around the question whether time is of the essence in a contract.

The Tribunal noted that the supply of material in the instant case was not for any specific purpose or urgent requirement. The tender was a global tender for general requirement. Besides, the contract provides for imposition of LD and/or termination of the contract. It may also be noticed that ONGC could extend the time for delivery and in fact ONGC did extend the delivery period without levying any LD. These and other stipulations in the contract are a clear indication that the time was not the essence of contract.

The Arbitral Tribunal, at the outset, had held that merely having a clause in the contract making time the essence of it would not be determinative; rather, an overall view having regard to all the terms of contract are to be taken into consideration. Further, they noted that contracts containing provision for extension of time or payment of penalty on default would dilute the obligation of timely performance and render the clauses imbuing time as essence of the contract ineffective. Additionally, the Arbitral Tribunal also noted that generally, under construction contracts, time is not the essence.

The Supreme Court agreeing with the Tribunal held that it is now settled that ‘whether time is of the essence in a contract’, has to be culled out from the reading of the entire contract as well as the surrounding circumstances. Merely having an explicit clause may not be sufficient to make time the essence of the contract. As the contract was spread over a long tenure, the intention of the parties to provide for extensions surely reinforces the fact that timely performance was necessary. The fact that such extensions were granted indicates ONGC’s effort to uphold the integrity of the contract instead of repudiating the same.

Comments

Post a Comment

Most viewed this month

Deposit Of Minimum 20% Fine/Compensation U/s 148 NI Act Mandatory

In OP(Crl.).No.348 OF 2019, T.K.SAJEEVAN vs FRANCIS T.CHACKO, the appeal was filed against the order of the lower court to deposit 25% of the fine before filling of appeal. The appellant argued that the deposit introduced through the Section 148 of the NI Act after amendment was directory in nature as it used the term 'may' while mentioning the issue of deposit. The Kerala High Court however disagreeing held that in view of the object of the Legislature while incorporating Section 148 into N.I. Act, the word 'may' will have to be read as 'shall'. The imposition of payment contemplated under Section 148 N.I. Act cannot be restricted to some prosecutions and evaded in other prosecutions. Since the amount directed to be deposited being compensation, undoubtedly, it is liable to be ordered to be deposited irrespective of the nature of the prosecution. Therefore, the word 'may' can only be taken to have the colour and meaning of 'shall' and there
Post a Comment
Read more

NCLT - Mere admission of receipt of money does not qualify as a financial debt

Cause Title : Meghna Devang Juthani Vs Ambe Securities Private Limited, National Company Law Tribunal, Mumbai, CP (IB) No. 974/MB-VI/2020 Date of Judgment/Order : 18.12.2023 Corum : Hon’ble Shri K. R. Saji Kumar, Member (Judicial) Hon’ble Shri Sanjiv Dutt, Member (Technical) Citied:  Carnoustie Management India Pvt. Ltd. Vs. CBS International Projects Private Limited, NCLT Swiss Ribbons Pvt. Ltd. & Anr vs. Union of India & Ors. (2019) Sanjay Kewalramani vs Sunil Parmanand Kewalramani & Ors. (2018) Pawan Kumar vs. Utsav Securities Pvt Ltd 2021 Background Application was filed under section 7 of the Insolvency and Bankruptcy Code, 2016 alleging loan of Rs, 1.70 cr is due. The Applicate identified herself as the widow and heir of the lender but could not produce any documents proving financial contract between her Late husband and the CD but claimed that the CD has accepted that money was received from her husband. The applicant subsequently filed rejoinder claiming the debt t
Post a Comment
Read more

Jurisdiction of consumer forum is not ousted even if the other party has filed suit on the same matter in Civil Court

In Yashwant Rama Jadhav v. Shaukat Hussain Shaikh, First Appeal No. 1229 of 2017, decided on 18.11.2017,  the grievance of the petitioner before the National Consumer Disputes Redressal Commission was that appellants/complainants had entered into agreements with the respondents for purchase of residential flats, which the respondents were to construct and despite paying the substantial amount to the respondents, the construction of the flats had not been completed. The State Commission dismissed the complaints and ruled in favor of respondents against which the appellants approached the National Commission. The NCDRC held that Section ‘3’ of the Consumer Protection Act, to the extent it is relevant provides that the provisions of the Act shall be in addition and not in derogation of the provisions of any other law for the time being in force. Thus the remedy available under the Consumer Protection Act is an additional remedy, which Parliament has made available to a consumer. Even
Post a Comment
Read more